Subcontractor Rights

62 Florida cases classified under this topic · sorted by citation count · browse and sort

• Fulghum v. State
  92 Fla. 662· Fla.· 1926-08-21 ·cited 65×
  A surety on a contractor's performance bond for public road work appeals a judgment allowing a subcontractor to recover compensation for labor and materials supplied. The Florida Supreme Court affirms, holding that the bond contains the statutory obligation to pay all persons sup
• Health Application Sys., Inc. v. Hartford Life & Accident Ins. Co. & State of Fla. Dep't of Health & Rehabilitative Servs.
  381 So. 2d 294· Fla. 1st DCA· 1980-03-12 ·cited 50×
  Health Application Systems, Inc. (HAS) appealed dismissal of its counterclaim against the State of Florida Department of Health and Rehabilitative Services (HRS) and third-party complaint against Hartford Life and Accident Insurance Company arising from a Medicaid drug program co
• J. S. & H. Constr. Co. v. Richmond Cnty. Hosp. Auth.
  473 F.2d 212· 5th Cir.· 1973-01-30 ·cited 38×
  The court held that the arbitration provision in the prime contract was effectively incorporated by reference into the subcontract, making it binding on the subcontractor.
• Autrey v. Williams AND Dunlap
  343 F.2d 730· 5th Cir.· 1965-02-24 ·cited 30×
  The court held that the Miller Act's jurisdictional provisions apply to suits on payment bonds for Capehart Act projects, and that a prime contractor's failure to act on a subcontractor's draw request constituted a breach of contract.
• Cent. Steel Erection Co. v. Merrill F. Will and Karl K. Larsen
  304 F.2d 548· 9th Cir.· 1962-05-16 ·cited 30×
  The court held that a subcontractor could recover on a quantum meruit basis for extra work when no agreement was reached on compensation, and that the Miller Act surety was liable for such recovery. The court also recalculated the award due to inadequate findings.
• John W. Johnson, Inc. v. Basic Constr. Co., Inc.
  429 F.2d 764· D.C. Cir.· 1970-06-22 ·cited 24×
  The court held that Basic breached its subcontract by failing to issue a written change order and commit to payment for extra work, and that the prime contract's Disputes Clause was not applicable to the subcontractor.
• Cont'l Cas. Co., Inc. v. Allsop Lumber Co., Inc.
  336 F.2d 445· 8th Cir.· 1964-08-26 ·cited 24×
  The court held that federal district courts have jurisdiction over actions on Capehart Act payment bonds under 28 U.S.C. § 1352, and that service of process on individual defendants outside the state was valid. The court also found that the notice requirements of the bond were sa
• Beaconwear Clothing Co. v. The United States
  355 F.2d 583· Ct. Cl.· 1966-01-21 ·cited 22×
  The second assignment of contract proceeds to a subcontractor was void under the Assignment of Claims Act, and the subcontractor could not claim status as a beneficiary of the first assignment to a bank because it did not participate in financing. The bank, having been paid in fu
• Edward E. Morgan Co., Inc. v. United States
  230 F.2d 896· 5th Cir.· 1956-02-23 ·cited 22×
  The court held that the trial court erred in admitting evidence of custom and in refusing to give proper jury instructions regarding contract interpretation.
• United States For the Use & Benefit of Heller Elec. Co., Inc. v. William F. Klingensmith, Inc.
  670 F.2d 1227· D.C. Cir.· 1982-02-02 ·cited 17×
  A surety under the Miller Act is liable for delay damages incurred by a subcontractor, and when both parties to a construction contract cause delays, damages must be apportioned based on the extent of each party's fault.
• The United States For the Use & Benefit of Citizens Nat'l Bank OF Orlando v. Stringfellow
  414 F.2d 696· 5th Cir.· 1969-07-30 ·cited 16×
  The court held that the district court's determination of the reasonable value of the dirt work performed by the subcontractor was not clearly erroneous and affirmed the award.
• J. J. Henry Co., Inc. v. The United States
  411 F.2d 1246· Ct. Cl.· 1969-06-20 ·cited 16×
  The court held that the plaintiff's claims for Fifth Amendment 'taking' of plans and for equitable lien against retained funds were without merit.
• United States for the Use & Benefit of Samuel J. Pickard v. S. Constr. Co., Inc.
  293 F.2d 493· 6th Cir.· 1961-08-03 ·cited 16×
  The court held that a material breach justifying quantum meruit recovery requires a fundamental breach going to the root of the contract, and that the $35,000 payment was a compulsory counterclaim that should have been raised in the first filed action.
• United States for the use & benefit of Frank A. Trucco & Sons Co. v. Bregman Constr. Corp.
  256 F.2d 851· 7th Cir.· 1958-06-20 ·cited 14×
  The court held that by filing a lawsuit for damages against the subcontractor's surety, the general contractor waived its right to demand arbitration of the dispute under the subcontract.
• United States v. Henke Const. Co.
  157 F.2d 13· 8th Cir.· 1946-07-18 ·cited 14×
  The court held that the subcontractor was not entitled to damages for the brick controversy, as the trial court's findings were supported by evidence, and that the subcontractor was only entitled to the additional cost of ceramic tile, not overhead or profit.
• United States v. John Kerns Const. Co.
  140 F.2d 792· 8th Cir.· 1944-02-10 ·cited 14×
  A party preventing contract completion within the stipulated time waives the right to claim liquidated damages for delay, and this waiver can be established by conduct or oral agreement.
• Allied Gen. Contractors v. Superior Asphalt Co.
  397 So. 2d 727· Fla. 5th DCA· 1981-04-15 ·cited 12×
  The court held that attorney fees awarded in an action on a payment bond must be computed under the specific limitations of Fla. Stat. § 627.756(2), not the general provisions for lien enforcement under Fla. Stat. § 713.29.
• Bd. OF Cnty. Comm'rs OF Okaloosa Cnty. v. Gulf Pipeline Co., Inc.
  168 So. 2d 757· Fla. 1st DCA· 1964-11-17 ·cited 12×
  The court held that while a legal claim for the 15% overrun was barred by a release, the subcontractor had an equitable claim for half of the costs associated with that overrun due to the government's inaccurate estimate and insufficient time for bidders to verify it.
• Freeman Contractors, Inc. v. Cent. Sur. & Ins. Corp.
  205 F.2d 607· 8th Cir.· 1953-07-02 ·cited 12×
  The court held that the trial court erred in denying Freeman Contractors a jury trial on the issues of whether Kiewit breached the contract through unreasonable delays and whether Kiewit promised to reimburse Freeman Contractors for those delays.
• Great Lakes Const. Co. v. Republic Creosoting Co.
  139 F.2d 456· 8th Cir.· 1943-12-10 ·cited 12×
  The court held that the subcontractor's intervention was timely because the 'final settlement' date was November 13, 1940, not August 24, 1940, and that the general contractor breached the subcontract by failing to provide the work site on time.
• Maxum Founds., Inc. v. Salus Corp. & United Pac. Ins. Co.
  779 F.2d 974· 4th Cir.· 1985-12-18 ·cited 11×
  The court held that the subcontract incorporated the general contract's arbitration clause by reference, and Salus did not waive its right to arbitration through participation in discovery. The court also vacated the district court's finding of a settlement agreement.
• Columbia Cas. Co. v. Right Reverend Patrick Barry
  111 Fla. 517· Fla.· 1933-07-13 ·cited 11×
  Columbia Casualty Co. and contractor Louis Fleisher Construction Co. appealed a judgment for the building owner, Right Reverend Patrick Barry, arising from contractor default and non-payment of sub-contractors. The Florida Supreme Court affirmed, holding that contractual provisio
• Elte, Inc. v. S. S. Mullen, Inc.
  469 F.2d 1127· 9th Cir.· 1972-11-08 ·cited 10×
  The court held that a subcontractor is entitled to damages for work performed due to the prime contractor's breach in failing to provide a suitable quarry, and that prejudgment interest is allowable on liquidated or determinable unliquidated claims.
• Beacon Constr. Co. OF Mass., Inc. v. Prepakt Concrete Co.
  375 F.2d 977· 1st Cir.· 1967-04-12 ·cited 10×
  The court held that the subcontractor was not bound by the arbitration clause in the general contractor's assignment contract, nor by the disputes clause in the government's general conditions, as these clauses were not properly incorporated by reference to bind the subcontractor
• Ottinger v. United States
  230 F.2d 405· 10th Cir.· 1956-01-24 ·cited 10×
  The court held that interest was properly allowed on the subcontractor's recovery because the subcontract fixed the value of services, making the amount due calculable and certain under Oklahoma law.
• LEO Spear Constr. Co., Inc. v. The Fid. & Cas. Co. OF NEW York & BrookfieldBaylor
  446 F.2d 439· 2d Cir.· 1971-07-01 ·cited 8×
  The dissenting judge believes the appellate court should not have reversed the district court's judgment for tortious interference with business relations, as the findings were supported by substantial evidence.
• Golden W. Constr. Co. v. United States for the Use & Benefit of George Bernadot
  304 F.2d 753· 10th Cir.· 1962-05-31 ·cited 8×
  The court held that the Miller Act claim was timely filed, a letter detailing an oral agreement was admissible, the surety was not prejudiced by contract modifications, and interest against the surety should only be awarded from the date of suit commencement.
• Trinity Universal Ins. Co. v. Smithwick
  222 F.2d 16· 8th Cir.· 1955-05-02 ·cited 8×
  The court held that the surety bond protected the subcontractor, and the surety could not limit its liability by contract or raise defenses not timely asserted. The statutory penalty and attorney fees were properly awarded.
• Nickel v. Pollia
  179 F.2d 160· 10th Cir.· 1950-01-03 ·cited 8×
  The court held that there was no privity of contract between the subcontractor and the FPHA, and the subcontractor's stoppage of work constituted a breach of contract, warranting termination.
• Coatings Mfrs., Inc. v. DPI, Inc.
  926 F.2d 474· 5th Cir.· 1991-03-18 ·cited 6×
  The court held that Mississippi law, as interpreted by analogy to similar statutes, does not permit suppliers of rental equipment to utilize the stop payment notice statute.
• W.F. Magann Corp. v. Diamond Mfg. Co., Inc.
  775 F.2d 1202· 4th Cir.· 1985-10-22 ·cited 6×
  The court held that while Magann breached the contract due to defective specifications and differing site conditions, the award of profits and booster pump rental as quantum meruit damages was improper and required remand for recalculation.
• Wash. Metro. Area Transit Auth. v. Norair Eng'g Corp. & Emps. Commercial Union Ins. Co.
  553 F.2d 233· D.C. Cir.· 1977-04-06 ·cited 6×
  The court held that the subcontract's language was not sufficiently clear to incorporate the prime contract's administrative disputes clause by reference, and therefore, the subcontractor was not required to exhaust administrative remedies before filing suit.
• Seaboard Sur. Co. v. United States for Use & Benefit of C.D.G., Inc.
  355 F.2d 139· 9th Cir.· 1966-01-17 ·cited 6×
  The court held that a subcontractor wrongfully terminated can elect to sue for the reasonable value of work performed, and that pre-judgment interest is only proper on damages that are certain or capable of being made certain by calculation.
• Price v. H. L. Coble Constr. Co.
  317 F.2d 312· 5th Cir.· 1963-05-08 ·cited 6×
  A party furnishing labor and materials under a direct contract with a subcontractor is covered by the statutory payment bond, and recovery includes profits calculated based on the contract price.
• Shepard Eng'g Co. v. United States
  287 F.2d 737· 8th Cir.· 1961-03-16 ·cited 6×
  Title to materials acquired by a contractor vests in the government upon partial payment, even if the materials are warehoused by a subcontractor, and this vests title paramount to any rights the subcontractor may claim.
• Ogden Elec. Co. v. Engineers
  151 F.2d 657· 10th Cir.· 1945-11-01 ·cited 6×
• Battista v. Horton
  128 F.2d 29· D.C. Cir.· 1942-05-11 ·cited 6×
  The court held that the subcontractor was entitled to the balance of the contract price, as the contract did not require a lien release and the subcontractor had no right to file a lien.
• Gramling v. Chapman
  81 Fla. 362· Fla.· 1921-03-19 ·cited 6×
  This case concerns whether a material man can establish a lien on a property when the contractor abandons the job and the owner uses funds from a surety bond to complete the building. The court found that the material man's lien rights are limited to the amount actually owed to t
• United States for the Use & Benefit of AETNA Drywall Contractors, Inc. v. AETNA Cas. & Sur. Co.
  725 F.2d 650· 11th Cir.· 1984-02-24 ·cited 4×
  The court held that the district court erred in granting a directed verdict based on the statute of limitations and failure to apportion damages.
• Hummer v. The Adm'r of the Nat'l Aeronautics & Space Admin.
  500 F.2d 1383· C.C.P.A.· 1974-08-22 ·cited 4×
  The court held that the invention was first reduced to practice when the ATS-1 satellite was successfully orbited and transmitted signals, and that NASA is entitled to title to the patent under section 305 of the National Aeronautics and Space Act of 1958.
• United States For the Use of Howard Steel Co. v. United Pac. Ins. Co.
  427 F.2d 366· 7th Cir.· 1970-06-02 ·cited 4×
  The court held that the trial court's findings of fact were supported by substantial evidence and not clearly erroneous, and that the denial of a new trial was not an abuse of discretion.
• Mullinax Eng'g Co. v. Platte Valley Constr. Co.
  412 F.2d 553· 10th Cir.· 1969-06-24 ·cited 4×
  The court held that the subcontract obligated the prime contractor to ensure the subcontractor could begin and continue work without delay after May 15, and failure to do so constituted a breach of contract, making the prime contractor liable for damages.
• The United States v. Merritt-Chapman & Scott Corp.
  305 F.2d 121· 3d Cir.· 1962-06-29 ·cited 4×
  The court held that the trial court erred in excluding business records offered to prove the date of work completion, which was a prerequisite for maintaining an action on a Miller Act payment bond.
• Pinole Land Co., Inc. v. Baker
  287 F.2d 828· 9th Cir.· 1961-02-13 ·cited 4×
  The court held that oral promises to repair equipment, made before contract execution, could supersede written contract terms and establish a condition precedent to rental payment.
• United States v. SCI, Inc.
  828 F.2d 671· 11th Cir.· 1987-09-28 ·cited 3×
  The court held that the subcontractor could not recover delay damages from the general contractor due to a "no damages for delay" clause, but could amend its complaint to recover funds from a settlement between the general contractor and the VA. The court also modified the prejud
• Gulfside Supply, Inc. v. Fred Curtis, Inc.
  464 So. 2d 585· Fla. 2d DCA· 1985-01-25 ·cited 2×
  This case involves a dispute over funds owed by a general contractor (Curtis) to a subcontractor (Benjamin) after the subcontractor's breach. A supplier (Gulfside) that had obtained a judgment against Benjamin sought to garnish these funds. The appellate court affirmed some set-o
• Ludwig & Kibbey Enters. v. COX Steel & Supply, Inc.
  119 So. 2d 58· Fla. 1st DCA· 1960-03-10 ·cited 2×
  A property owner appeals a decree awarding full material-man's liens, challenging the trial court's interpretation of a contract provision requiring receipts and lien waivers to accompany progress payment applications. The appellate court reverses, holding that the contract provi
• John & Sal's Auto. Serv. Inc. v. Sinclair Ref. Co.
  264 F.2d 711· 2d Cir.· 1959-03-23 ·cited 2×
  The court held that it would not grant a preliminary injunction to reinstate a sublicense that was cancelled due to unsatisfactory service, even if a hearing was required before such a determination.
• United States Ex Rel. Expedia, Inc. v. Altex Enters., Inc.
  734 F. Supp. 972· M.D. Fla.· 1990-04-09 ·cited 1×
  The court held that venue is proper in the Middle District of Florida because the contract was performed in part within that district, and the Miller Act allows suit where the contract was performed.
• Metalizing Tech. Servs. LLC v. Berkshire Hathaway Specialty Ins. Co.
  S.D. Fla.· 2022-04-14
  The court held that permissive intervention is appropriate, but LEAD must provide evidence of its citizenship to establish federal jurisdiction.