C. C. HARGROVE, D/B/A HARGROVE PLASTERING COMPANY, APPELLANT,
v.
LITTLE CONSTRUCTION CO., INC., AND AETNA CASUALTY AND SURETY CO., INC., APPELLEES

4th Cir. | 1961-03-30
No. 8219
289 F.2d 61 United States Court of Appeals for the Fourth Circuit (1961)

AI-generated. These summaries, headnotes, and key points are machine-generated and may contain errors or omissions. Always verify against the full opinion text below. Not legal advice.


Holding

The court held that the subcontractor's claims for damages due to delays were without merit, leading to an affirmation of the lower court's judgment.


Facts & Procedural History

A subcontractor sued the general contractor for damages caused by alleged delays in a hospital construction project. The trial court found no unreason…

The full statement of facts, procedural history, and disposition for this case are member content.

Join FLexlaw to unlock all legal intelligence

© FLexlaw, Inc. — AI-generated enrichments are proprietary. All rights reserved.


Opinion of the Court
PER CURIAM.

PER CURIAM.

This is an action by a subcontractor, a plasterer, against the general contractor on the construction of an addition to a hospital. The claim is for damages the subcontractor says he suffered because of delays in the work.

The case was tried by the District Court without a jury. The District Court found there was no unreasonable delay and the work of the subcontractor was substantially completed on schedule. It also found that the subcontractor did not complain of any delay until sometime after the work was substantially completed. When, finally, he did complain of delay in the work of the tile subcontractor, the defendant suggested he submit an itemized statement of the expense to which he had been put by reason of the claimed delay, offering to back charge the tile setter by that amount and to give the plaintiff credit for it. The plaintiff did not submit such a statement, but, some months later, entered into a final settlement of the contract and of all of the rights of the parties under it.

There is evidence which supports these findings. We accept them, as we must, and the findings lead necessarily to the conclusion that the judgment for the defendant must be affirmed.

Affirmed.


Cases With Similar Vibessemantic neighbors from the corpus

Full citator, related cases, and AI research tools

Open in FLexlaw